民用工程合同书(16)

　　6.　drawings
　　7.　general obligations
　　8.　completion of works
　　9.　insurance of works
　　10.　damage to persons and property
　　11.　third party insurance
　　12.　accident or injury to persons
　　13.　remedy on contractor's failure to insure
　　14.　compliance with status and regulations ，etc.
　　15.　access to other contractors
　　16.　contractor to keep site clean
　　17.　labor
　　18.　materials and workmanship
　　19.　inspection of operations
　　20.　removal of improper work and materials
　　21.　suspension of work
　　22.　commencement time and time for completion
　　23.　extension of time for completion
　　24.　rate of progress
　　25.　liquidated damages for delay
　　26.　certification of completion of work
　　27.　guarantee against defects and liability for defective work
　　28.　alterations， additions and omissions
　　29.　adjustment of contract price due to variations in quantities
　　30.　plant， temporary works and materials
　　31.　measurement of quantities
　　32.　provisional sums
　　33.　payment and retention
　　34.　remedies and power on default by contractor
　　35.　special risks
　　36.　frustration and payments thereof
　　37.　settlement of disputes - arbitration
　　38.　notice
　　39.　default of employer
　　40.　language
　　41.　laws to be observed
　　no.:_________
　　this contract is made at_________， chesiville，parcheesi on_________month_________a.d._________between_________represented by_________， hereinafter called the"employer"and_________ registeredas a juristic person in_________（country.） with head office located at_________represented by_________who has been authorized to sign commitment binding on the saidjuristic person， hereinafter called the "contractor".
　　both parties agree as follows:
1　scope of work
　　in consideration of the payments to be made by the employer to the contractor as hereinafter mentioned， the contractorhereby convenes with the employer to execute， complete andmaintain the works in conformity with the provision of the contract.